Terms and Conditions

These terms are an agreement between you and:

• AllsWeb — an independent IT-services business operating allsweb.com
• Registered address: PN. 30 AC, Ground Floor, Kapil Vihar, Budhsinghpura, Sanganer, Jaipur, Rajasthan 302029, India
• Contact: support@allsweb.com · WhatsApp / phone +91 72328 80007 · +91 96360 54300

AllsWeb is the merchant of record for orders placed on this site. Payments are processed by Stripe (international) and Razorpay (India) and appear on your statement as ALLSWEB.

• AllsWeb / we / us — the team operating allsweb.com.
• You / Customer — the person or company placing an order.
• Order — a paid request for installation, customization, app submission, maintenance, update / upgrade, a managed service, or a Hire Us / custom build.
• Project — the workspace created for a product order; it owns your purchased services, requirements, files and invoices.
• Deliverable — what we hand over: source code, app builds (APK / AAB / iOS), configurations, documentation, or a completed store submission.

We install, configure, customize, submit to app stores, update and support third-party scripts and apps — including CodeCanyon products (6ammart, StackFood, 6Valley, Demandium, DriveMond, eFood, HexaCom, GroFresh and others), plus WordPress, Laravel, Flutter, React and Next.js work. We also build custom, first-party solutions (websites, SaaS, mobile apps, CRM / POS, AI automations, browser extensions and plugins) through Hire Us.

The exact scope of your order is fixed by your checkout line items, project requirements, and any written quote — not by general marketing copy on the site.

We use AI and automation to move faster — provisioning, scaffolding, checks and CI. You still get human judgment on architecture, security and the final release.

We sell digital services, not physical goods, so “delivery” means the work is performed and the result is made available to you. A service is delivered when, as applicable to your order:

• the script / app is installed and configured on your hosting and reachable, and / or
• the app build is submitted to Google Play / the App Store (approval timing is the store’s, not ours), and / or
• deliverables (source code, builds, configs, docs) are made available in your project — via your dashboard, a private GitHub repository, or a signed download link, and / or
• the agreed customization / integration / migration is completed and testable.

Typical catalog delivery is 1–3 working days after your requirements are complete. The delivery clock pauses until you submit the requirements we need (see below).

You agree to:

• Own a valid licence for any third-party script we work on
• Submit accurate, complete requirements (server / hosting, domain, branding, Firebase, Maps, gateways, store accounts) from your dashboard
• Review deliveries within the included revision window
• Keep hosting, domain and store accounts active and paid while we work
• Pay invoices on time for milestone / Hire Us projects

Prices are shown in USD on the catalog and at checkout. Catalog orders are paid 100% upfront via Stripe or Razorpay. Hire Us / custom builds follow your written quote, with a $300 minimum for first-party builds; small third-party-script customization starts from $30.

AllsWeb is not registered for GST, so invoices carry no separate Indian GST / tax line. You are responsible for any tax due in your own country. Full money rules are in the Payment Policy; refunds are in the Refund Policy.

Each service includes 2 revision rounds within the original scope, requested within 14 days of delivery. Please test fully and send all changes together so we can apply them in one round.

After the included rounds, new work is quoted as customization. Moving to a newer version of your script is the paid Update / Upgrade service (about 50% of the install price), not a free rework. If another developer changes our delivery afterwards, our warranty for that scope ends (see Support Policy).

After full payment, you own the deliverables we created for your project (your builds, configurations and documentation).

We keep ownership of the reusable internal tools, automation, AI prompts and templates we use across clients. Third-party scripts, themes, fonts and libraries stay under their own licences — you must hold a valid licence for each.

We treat your non-public information and uploaded secrets (keys, SSH, API credentials, keystores) as confidential, accessible only to the engineers on your project. Need a signed NDA before sensitive work? Email support@allsweb.com.

You may not use our services for illegal, fraudulent or harmful projects — malware, spam infrastructure, phishing, illegal gambling, or IP infringement. We may refuse or cancel such orders without refund. Full rules: Acceptable Usage Policy.

We deliver our work with reasonable skill and care. Beyond that, services are provided “as is” to the extent the law allows. We do not guarantee the uptime, security or future updates of third-party scripts, hosting or app stores outside our managed scope, nor any specific app-store approval, ranking, or revenue result. See the Disclaimer.

To the extent permitted by law, our total liability for any claim is capped at the fees you paid for that service in the 12 months before the claim. We are not liable for indirect or consequential loss (lost profit, data, goodwill), for data loss on your server, for store rejections, or for actions by payment providers or third parties beyond our control. Nothing here limits liability that cannot be limited by law.

Either side may end the relationship by email. Completed milestones stay payable. Unused prepayment is handled per the Refund Policy. We may suspend or cancel service immediately for non-payment, an Acceptable Usage breach, or fraud / abusive chargebacks — and any lifetime support already granted may end on a material breach.

• Force majeure — neither side is liable for delays or failures caused by events beyond reasonable control (outages of hosting, payment, app stores or third-party APIs, natural events, or government action).
• Assignment — you may not transfer your order without our consent; we may assign these terms to a successor of our business.
• Severability — if any clause is unenforceable, the rest stays in force.
• No waiver — not enforcing a term once does not waive our right to enforce it later.
• Entire agreement — your order confirmation, these terms and the linked policies are the whole agreement and replace earlier discussions.
• Notices — formal notices to us go to support@allsweb.com; to you, the email on your account.
• No third-party rights — these terms are between you and AllsWeb only.

These terms are governed by the laws of India. We try to resolve every dispute through support first — please email support@allsweb.com before any chargeback. Subject to any mandatory consumer rights in your own country, the courts of Jaipur, Rajasthan, India have exclusive jurisdiction.

We may update these terms. Important changes are emailed to registered users at least 7 days before they apply. Continuing to use the site or services after that means you accept the update.

Questions about these terms: support@allsweb.com · WhatsApp / phone +91 72328 80007 · AllsWeb, PN. 30 AC, Ground Floor, Kapil Vihar, Budhsinghpura, Sanganer, Jaipur, Rajasthan 302029, India.